A subcontractor agreement is a legal document that a general contractor uses to employ a subcontractor on a building project. This contract is a legally binding agreement that describes the parameters of a minor task inside the larger project that will be done by an entity other than the general contractor. Subcontractor agreements are often entered into between the contractor and another firm, with no involvement from the customer.
If you are working as or with a subcontractor, you must know what exactly you will deal with before commencing.
Many chief contractors that appoint third-party contractors to complete their work sign-up with these agreements for assurance. These papers or bonds are contractual agreements between the two parties that enable smooth functioning.
With the aid of this agreement, if something goes wrong, you can easily sort disputes according to the terms of the bond. Read on and identify more insights about a subcontractor agreement. You will grasp many details about the agreement in this guide for the finest assistance.
A subcontractor agreement is similar to the bonds drafted between the employees and employers. The most prominent variation between them is that the two have a different scope of work and responsibilities to meet. The most basic idea behind drafting this agreement is to mention the tasks are being subcontracted.
The bond must also mention the materials that the subcontractor must supply and the ones that thesupplier will extend. For instance, a subcontractor bond between a trainer and an outsourced trainer will comprise details about where and when the training will occur. The agreement would also contain the number of trainers that would serve. The responsibilities of each trainer and other provisions like training areas are also clearly listed in these agreements.
A chief contractor might subcontract some other tasks like electrical needs to an electric firm for construction industries. The agreement would usually mention this bond's light sockets, installations, and other details.
It can also mention supply details like cabling and more. Altogether, the basic idea of creating a subcontractor agreement is to outsource the work efficiently. In these agreements, tasks are mentioned clearly; both the parties need to agree to the terms before starting work. Doing so reduces risks and even lays down clear terms in case of disputes.
A subcontractor is a person or company who undertakes work for a contractor as part of a bigger project. Contractor subcontractor agreements are most popular in the construction industry, where specialised abilities are rented out to accomplish large construction projects. A hired project manager, for example, may employ a bricklaying business to construct a new school in a new suburban development. A subcontractor agreement is thus a legal document between a contractor and a subcontractor that lays out the terms and conditions of the work to be completed.
What are the perks of subcontractors, and why are they used?
Subcontracting offers contractual work to third-party individuals and is commonly found in transport, construction, and similar industries. The role can extend some exciting benefits to main contractors.
First of all, hiring a subcontractor can save you on heavy expenses. You can hire these individuals on a short-term basis while the contractor operates a large-term project. Subcontractors can also be a cheap alternative in comparison to full-time workers. Next, these contractors also have expertise in specific niches or extend expert quality services. Subcontractors are highly beneficial for your work, and they deliver superior services that regular employees cannot provide.
When a contractor employs a contractor, who then contracts another subcontractor to conduct work as part of a huge project, it may get quite complex. The danger here is that information will be misread, money will be missing, and work will not be finished on schedule. All of these scenarios have the potential to severely ruin a project. A subcontractor agreement ensures that all parties involved keep operations tight, focused, and consistent.
Depending on the size and scope of your company and projects, you may need to employ subcontractor agreements on a regular basis. A subcontractor agreement will be required each time you need to outsource services to finish a task. As a contractor or project manager, you most certainly have a solid sense of the gaps that need to be filled to complete a project. Even before taking on a new customer, you should go out to your network to get subcontractors to ensure the job is completed on time. A subcontractor agreement will also be required if your present subcontractors are no longer able to execute their duties and must be replaced. Finally, if extra time is needed to finish the task, you may need to employ subcontractor agreements to prolong contracts.
A qualified project manager understands the project's goal while also keeping an eye on all of the moving components that make the project a reality. Every subcontractor agreement must be tailored to the services that are requested. When there is too much information, the job of the subcontractor becomes muddled. There is insufficient information, and it is unclear what each subcontractor is expected to do. The key to a high-quality subcontractor service agreement is that it articulates the scope of work required from the subcontractor precisely.
upon completion? Or will you pay in instalments? Whatever way you pick, make it very clear in your agreement and keep your commitments.
The details of this agreement can differ from industry to industry. Certain individuals that hire the main contractor may not need to revise their agreements for long. So, preparing a one in all bond is the most favorable key for them. Individuals may need a detailed and specific agreement to lay out the job details in other cases.
The must-haves usually come down to both parties' needs and requirements. If you need more details in your subcontractor agreement, you might need expert assistance. So, go for a well-skilled lawyer to assist you in completing the task with skill and perfection.
Tips for writing a Subcontractor Agreement
Mention all the necessities of the project
Outlining the portion of the assignment that comes under the subcontractor's duties is a must. List details of how the subcontractor's duties will fit perfectly well in the agreement. For instance, if the need is to write a copy for a magazine, introduce the design and other layouts to understand better the content needed.
Mention the provisions and due dates
As you will have to attach a copy of the agreement to your work, you must prefer to complete it at least five days before the due date. It permits time for reviewing and editing as well.
Mention the payment terms
You will first have to receive the payments from your clients to pay the subcontractor. Thus, if the terms in your agreement with the client are 14 days, then you prefer to keep the time duration for the subcontractor 20 to 30 days. Doing so gives you ample time to receive the client's payments, deposit them if needed and pay the contractor within time.
Draft the contract and send it for review
The contract should not be very long; it can be crisp paperwork that lists all necessary details. Differentiate both parties well in the contract so that all your terms and aspects are clear. Remove confusion and review it well before finalizing the contract.
Mention how well you manage disputes
Rather than merely relying on legalities, which are quite costly, you can settle disputes and breaches in your unique way. Doing so gives both parties enough space and time to work calmly and agree on a settlement.
Once you have completed the document, a final review is a must. You and the opposite party must agree to all the listed terms to fully understand the subcontractor agreement. Look for errors and give it a final touch-up to proceed.
If you're a busy contractor, you'll almost certainly use the same subcontractors again and again. Your connections are one of your most valuable assets, allowing you to charge your clients extra for access to your database of trustworthy professionals. That is why it is crucial to develop these connections and guarantee that they are paid regularly and within a fair time frame. Nothing will wreak havoc on your relationships more than failing to pay your subcontractors. When creating a subcontractor agreement, be specific about what you're willing to pay and when. Will you, for example, pay a percentage upfront and a percentage
Hiring subcontractors is quite beneficial. It can assist you in saving additional expenses and getting the finest possible services for your work. However, making a suitable subcontractor agreement is quite necessary for success. Use the given guidelines and create the finest possible agreement for seamless work. Acquire the best details and make the most benefit from your business.
Use Awesome Sign to get started, and sign your pdf documents effortlessly.
This Master Subcontractor Agreement (this “Agreement” or this “Subcontractor Agreement), is entered into and made effective as of (add a corresponding date) (the “Effective Date”), by and between:
[Sender.Company], the company with offices located at ................................................................ (add a corresponding address) (“Prime”), and
[Client.Company], the company with offices located a ............................................................... (add a corresponding address) (“Subcontractor”).
1.Prime has existing or prospective customer contracts for which Prime may require support; and
2.Subcontractor has been identified by Prime as a potential subcontractor as it has certain expertise and capabilities which may be required under such contracts; and
3.The parties wish to set forth the terms and conditions upon which any Subcontractor support may be provided to Prime.
NOW THEREFORE, in consideration of the foregoing, and of the mutual covenants and agreements set forth herein, the receipt and sufficiency of which is hereby acknowledged, the parties, intending to be legally bound, agree as follows:
The following capitalized terms will have the following definitions under this Agreement:
1.“Contract” means Prime’s contract with the Customer for which the Subcontractor may provide support pursuant to Task Orders issued under this Agreement.
2.“Customer(s)” means customers of Prime for whom Services or Deliverables are to be performed under a Task Order.
3.“Deliverables” means those items, products and materials to be provided to Prime by Subcontractor, as specified on a Task Order.
4.“Firm Fixed Price (FFP)” means an agreed upon fixed price for the Services and Deliverables to be provided pursuant to a Task Order.
5.“Intellectual Property Rights” means world-wide, common-law and statutory rights associated with (i) patentable inventions, patents and patent applications, divisions, continuations, renewals, reissuance and extensions, thereof, (ii) copyrights, copyright applications and copyright registrations, “moral” rights and mask work rights, (iii) the protection of trade and industrial secrets and confidential information, and (iv) trademarks, trade names, service marks, and logos (collectively “Trademarks”).
6.“Open Source” means any software having license terms that require, as a condition of use, modification, or distribution of the software that such software or other software combined or
distributed with such software be (i) disclosed or distributed in source code form, (ii) licensed for the purpose of making derivative works, and (iii) redistributable at no charge.
7.“Other Direct Costs” means costs normally incurred in the operation of a business, such as postage, telephone and internet charges, office supplies and overhead.
8.“Party or Parties” means the signatories to this Agreement when referred to, respectively, individually or collectively.
9.“Pre‐Existing Intellectual Property” means any Intellectual Property that has been conceived or developed by either party or any third party before Subcontractor renders any services under this Agreement or any Task Order or that is conceived or developed at any time wholly independently of the Services and Deliverables.
10.“Services” means all work performed by Subcontractor under this Agreement pursuant to a Task Order, as well as materials used by Subcontractor in performing its obligations under a Task Order.
11.“Task Order” means a written document executed by the Parties authorizing Subcontractor to perform Services and/or provide Deliverables in accordance with such Task Order. For clarity, any contract for services entered into through an online freelance or similar website shall be construed as a Task Order under the terms of this Agreement.
12.“Time and Materials (T&M)” means Services performed at an hourly rate wherein the actual cost of hours worked and materials used in the performance of the Services are charged to Prime. Equipment and other depreciable assets are not to be charged.
Prime shall have no obligation to award any work or Task Order under this Agreement. However, should any work be awarded to the Subcontractor, the parties agree that such work will be subject to the terms and conditions of this Agreement. The Subcontractor shall, in accordance with Task Orders issued by Prime and agreed to by Subcontractor, perform work assignments to provide expert Services, advice, and/or Deliverables. A Task Order shall be considered in effect and duly authorized only upon written agreement of both parties.
Each Task Order shall provide, at a minimum, the following data:
All Task Orders incorporate the terms and conditions of this Subcontract, whether stated explicitly or not. In the event of conflict or inconsistency between a Task Order and this Agreement, the terms and conditions of this Agreement shall take precedence, unless specifically stated otherwise in the Task Order.
Unless otherwise terminated as provided herein, the term of this Subcontractor Agreement shall start on the Effective Date and end of the year (add a corresponding number) thereafter. Should a Task Order be authorized during the term of this Agreement, which provides for completion subsequent to the end date of this Agreement, then the Task Order shall be additionally construed as a written modification of this Agreement, which extends the end date of this Agreement to coincide with the Task Order completion date.
INVOICING & PAYMENT TERMS
Prime shall have the right at any time to set-off any amounts now or hereafter owing by Subcontractor to Prime under any Task Order or otherwise, against amounts which are then or may thereafter become due or payable to Subcontractor under this Agreement.
Upon notice to Subcontractor, Prime may change any requirement in a Task order relating to undelivered Services and/or Deliverables. If such change reasonably affects the price or schedule, the Subcontractor will notify Prime within number business days of such, and the parties will negotiate an equitable adjustment in the fees, charges and/or schedule and make appropriate amendments to the applicable Task Order. Prime shall have no obligation to the Subcontractor for any changes to a Task Order that were not authorized in writing by Prime.
Subcontractor understands that by signing this Agreement, it is appointing Prime as an exclusive representative with respect to Customers to whom Subcontractor is introduced and/or to whom Subcontractor is assigned by Prime, as to the subject matter of Prime’s retention of Subcontractor hereunder. Subcontractor agrees that the relationship between Subcontractor and any such Customers, for purposes of this Agreement and whether or not this Agreement or any Task Orders hereunder is/are terminated, begins upon the initial disclosure of a potential assignment to Subcontractor by Prime. During the term of this Agreement and for number months following termination of this Agreement, Subcontractor shall not, directly or indirectly, either as an organization, as an individual, as an employee or member of a partnership, or as an employee, officer, director or stockholder of any corporation, or in any other capacity, solicit or accept, or advise anyone else to solicit or accept, any business that competes directly with Prime from any such Customers, or from the personnel of any Customers to whom Subcontractor was introduced pursuant to this Agreement. In addition, Subcontractor shall not directly or indirectly use or make available to any person, firm, or corporation the knowledge of the business of Prime gained by Subcontractor during the term of this Agreement.
INTELLECTUAL PROPERTY RIGHTS
1.Retained Rights. Each party will retain all right, title, and interest in and to its own Pre‐Existing Intellectual Property irrespective of any disclosure of such Pre‐Existing Intellectual Property to the other party, subject to any licenses granted herein.
2.Pre‐Existing Intellectual Property. Subcontractor will not use any Subcontractor or third party Pre‐ Existing Intellectual Property in connection with this Agreement unless Subcontractor has the right to use it for Prime or the Customer’s benefit. If Subcontractor is not the owner of such Pre‐Existing Intellectual Property, Subcontractor will obtain from the owner any rights as are necessary to enable Subcontractor to comply with this Agreement.
3.Subcontractor grants Prime a non‐exclusive, royalty‐free, worldwide, perpetual and irrevocable license in Subcontractor and third party Pre‐Existing Intellectual Property, to the extent such Pre‐ Existing Intellectual Property is incorporated into any Deliverable, with the license including the right to make, have made, sell, use, reproduce, modify, adapt, display, distribute, make other versions of and disclose the property and to sublicense others to do these things.
4.Subcontractor will not incorporate any materials from a third party, including Open Source or freeware, into any Deliverable unless
(i) Subcontractor clearly identifies the specific elements of the Deliverable to contain third party materials in the applicable Task Order,
(ii) Subcontractor identifies the corresponding third party licenses and any restrictions on use thereof in the applicable Task Order, and
(iii) approval is given by Prime as evidenced by a signed Task Order (or other written and fully executed agreement).
Subcontractor represents, warrants and covenants that Subcontractor has complied and shall continue to comply with all third party licenses (including all open source licenses) associated with any software components that will be included in the Deliverables or any other materials supplied by Subcontractor. Subcontractor shall indemnify Prime against any losses and liability incurred by Prime and any Customer due to failure of Subcontractor to meet any of the requirements in any of the third party licenses.
5.Ownership of Deliverables. Subject to Subcontractor and third party rights in Pre‐Existing Intellectual Property, all Deliverables, whether complete or in progress, and all Intellectual Property Rights related thereto shall belong to Prime, and Subcontractor hereby assigns such rights to Prime. Subcontractor agrees that Prime will own all patents, inventor’s certificates, utility models or other rights, copyrights or trade secrets covering the Deliverables and will have full rights to use the Deliverables without claim on the part of Subcontractor for additional compensation and without challenge, opposition or interference by Subcontractor and Subcontractor will, and will cause each of its Personnel to, waive their respective moral rights therein. Subcontractor will sign any necessary documents and will otherwise assist Prime in securing, maintaining and defending copyrights or other rights to protect the Deliverables in any country. Subcontractor, its agents, employees, and Subcontractors will deliver the Deliverables to Prime in accordance with the schedule included in a Task Order.
6.No Rights to Prime Intellectual Property. Except for the limited license to use materials provided by Prime as may be necessary in order for Subcontractor to perform Services under this Agreement, Subcontractor is granted no right, title, or interest in any Prime Intellectual Property.
Confidential Information. For purposes of this Agreement, “Confidential Information” shall mean information or material proprietary to a Party or designated as confidential by such Party (the “Disclosing Party”) and all information provided by a Customer, as well as information about which a Party (the “Receiving Party”) obtains knowledge or access, through or as a result of this Agreement (including information conceived, originated, discovered or developed in whole or in part by Subcontractor pursuant to a Task Order). Confidential Information does not include: a) information that is or becomes publicly known without restriction and without breach of this Agreement or that is generally employed by the trade at or after the time the Receiving Party first learns of such information; b) generic information or knowledge which the Receiving Party would have learned in the course of similar employment or work elsewhere in the trade; c) information the Receiving Party lawfully receives from a third party without restriction on disclosure and without breach of a nondisclosure obligation; d) information the Receiving Party rightfully knew prior to receiving such information from the Disclosing Party to the extent such knowledge was not subject to restrictions on further disclosure; or (e) information the Receiving Party develops independent of any information originating from the Disclosing Party.
Prime Confidential Information. The following constitute Confidential Information of Prime and should not be disclosed to third parties: the Deliverables, discoveries, ideas, concepts, software in various states of development, designs, drawings, specifications, techniques, models, data, source code, source files and documentation, object code, documentation, diagrams, flow charts, research, development, processes, procedures, “know-how”, marketing techniques and materials, marketing and development plans, customer names and other information related to customers, price lists, pricing policies and financial information, this Agreement and the existence of this Agreement, the relationship between Prime and a Customer, and any Task Order issued under this Agreement. Subcontractor will not use Prime or Customer names, likenesses, or logos (Prime or Customer “Identity”). Subcontractor will not use or reference Prime or Customer Identity, directly or indirectly, in conjunction with any other clients or potential clients, any client lists, advertisements, news releases or releases to any professional or trade publications.
Non-Disclosure. The Parties hereby agree that during the term hereof and at all times thereafter, and except as specifically permitted herein or in a separate writing signed by the Disclosing Party, the Receiving Party shall not use, commercialize or disclose Confidential Information to any person or entity. Upon termination, or at any time upon the request of the Disclosing Party, the Receiving Party shall return to the Disclosing Party all Confidential Information, including all notes, data, reference materials, sketches, drawings, memorandums, documentations and records which in any way incorporate Confidential Information.
Right to Disclose. With respect to any information, knowledge, or data disclosed to Prime by the Subcontractor, the Subcontractor warrants that the Subcontractor has full and unrestricted right to disclose the same without incurring legal liability to others, and that Prime shall have full and unrestricted right to use and publish the same as it may see fit. Any restrictions on Prime’s use of any information, knowledge, or data disclosed by Subcontractor must be made known to Prime as soon
as practicable and in any event agreed upon before execution of a Task Order.
CONFLICT OF INTEREST
Subcontractor represents that its execution and performance of this Agreement does not conflict with or breach any contractual, fiduciary or other duty or obligation to which Subcontractor is bound. Subcontractor shall not accept any Task Order from Prime or work from any other business organizations or entities which would create an actual or potential conflict of interest for the Subcontractor or which is detrimental to Prime’s business interests.
Prime may terminate this Agreement and/or an individual Task Order for its convenience, without liability at any time, upon prior written notice to Subcontractor.
Subcontractor may terminate this Agreement upon thirty days prior written notice provided there are no open Task Orders at the time notice is given.
Prime may terminate this Agreement and/or any open Task Orders immediately for cause if the Subcontractor fails to perform any of its obligations under this Agreement or any Task Order issued hereunder or if Subcontractor breaches any of the warranties provided herein and fails to correct such failure or breach to Prime’s reasonable satisfaction within ten (10) calendar days (unless extended by Prime) following notice by Prime. Prime shall be entitled to seek and obtain all remedies available to it in law or in equity.
Upon termination of any Task Order issued hereunder, Subcontractor will immediately provide Prime with any and all work in progress or completed prior to the termination date. As Prime’s sole obligation to Subcontractor resulting from such termination, Prime will pay Subcontractor an equitable amount as determined by Prime for the partially completed work in progress and the agreed to price for the completed Services and/or Deliverables provided and accepted prior to the date of termination.
Upon termination or expiration of this Agreement or a Task Order issued hereunder, whichever occurs first, Subcontractor shall promptly return to Prime all materials and or tools provided by Prime or Customer under this Agreement and all Confidential Information provided by Prime or Customer to Subcontractor.
Any provision of this Agreement that, by its language or context implies its survival, shall survive any termination or expiration of this Agreement.
Subcontractor may not subcontract, either in whole or in part, Services authorized by a Task Order without prior written consent of Prime. If Prime Contracts consents to subcontracting of any portion of the work to be performed under a Task Order, the Subcontractor must first obtain, from each subcontractor, a written agreement that is the same as, or comparable to, the following Sections of this Agreement: Customer Interactions, Exclusivity, Intellectual Property Rights, Confidentiality, Conflict of Interest, Subcontracting, Warranties, Indemnification, Limitation of Liability, Insurance and any other flow-down provisions contained in the applicable Task Order.
Subcontractor warrants that:
The Services and Deliverables are original and do not infringe upon any third party’s patents, trademarks, trade secrets, copyrights or other proprietary rights,
It will perform the Services hereunder in a professional and workmanlike manner,
The Deliverables Subcontractor provides to Prime are new, of acceptable quality free from defects in material and workmanship and will meet the requirements and conform with any specifications set forth in any Task Order entered into under this Agreement,
It will take commercially reasonable precautions to prevent the introduction of Harmful Code in Deliverables and correspondence and other materials prior to delivery to Prime. “Harmful Code” shall include, without limitation, any code containing viruses, Trojan horses, worms or like destructive code, code that self-replicates or code that contains a “timeout” feature to prevent access and use at some future date,
It has all necessary permits and is authorized to do business in all jurisdictions where Services are to be performed,
It will comply with all applicable federal and other jurisdictional laws in performing the Services,
It has all rights to enter into this Agreement and there are no impediments to Subcontractor’s execution of this Agreement or Subcontractor’s performance of Services hereunder.
Subcontractor shall defend, indemnify, protect and hold harmless Prime, the Customer, and each of their officers, employees and agents from and against any and all losses, demands, attorneys’ fees, expenses, costs, damages, judgments, liabilities, causes of action, obligations or suits resulting from (1) any negligent act or omission or willful misconduct of Subcontractor, its personnel or approved subcontractors, (2) the breach of any provision of this Agreement by Subcontractor or its personnel or any approved subcontractors of Subcontractor, or (3) any claim that Intellectual Property provided by the Subcontractor under this Agreement infringes or misappropriates any third party Intellectual Property Right.
LIMITATION OF LIABILITY
EXCEPT AS SET FORTH BELOW, IN NO EVENT WILL EITHER PARTY BE LIABLE FOR ANY SPECIAL, INDIRECT, INCIDENTAL, OR CONSEQUENTIAL DAMAGES NOR FOR LOSS OF DATA, PROFITS OR REVENUE, COST OF CAPITAL OR DOWNTIME COSTS, NOR FOR ANY EXEMPLARY OR PUNITIVE DAMAGES, ARISING FROM ANY CLAIM OR ACTION, INCIDENTAL OR COLLATERAL TO, OR DIRECTLY OR INDIRECTLY RELATED TO OR IN ANY WAY CONNECTED WITH, THE SUBJECT MATTER OF THE AGREEMENT, WHETHER SUCH DAMAGES ARE BASED ON CONTRACT, TORT, STATUTE, IMPLIED DUTIES OR OBLIGATIONS, OR OTHER LEGAL THEORY, EVEN IF ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.
NOTWITHSTANDING THE FOREGOING, ANY PURPORTED LIMITATION OR WAIVER OF LIABILITY SHALL NOT APPLY TO SUBCONTRACTOR’S OBLIGATION UNDER THE INDEMNIFICATION OR CONFIDENTIAL INFORMATION SECTIONS OF THIS AGREEMENT OR EITHER PARTY’S LIABILITY TO THE OTHER FOR PERSONAL INJURY, DEATH OR PHYSICAL DAMAGE TO PROPERTY CLAIMS.
INSPECTION & ACCEPTANCE
Non-Conforming Services and Deliverables. If any of the Services performed or Deliverables delivered do not conform to Task Order requirements, Prime may require the Subcontractor to perform the Services again or replace or repair the non-conforming Deliverables in order to bring them into full conformity with Task Order requirements, at Subcontractor’s sole cost and expense. When the defects in Services and/or Deliverables cannot be corrected by re-performance, Prime may: (a) require Subcontractor to take necessary action, at Subcontractor’s own cost and expense, to ensure that future performance conforms to the requirements and/or (b) reduce any price payable under the applicable Task Order to reflect the reduced value of the Services performed and/or Deliverables delivered by Subcontractor and accepted by Prime.
Cover. If Subcontractor fails to promptly conform the Services and/or Deliverables to the Task Order requirements or specifications, or take action deemed by Prime to be sufficient to ensure future performance of the Task Order in full conformity with Task Order requirements, Prime may (a) by contract or otherwise, perform the services or subcontract to another subcontractor to perform the Services and reduce any price payable by an amount that is equitable under the circumstances and charge the difference in re-procurement costs back to Subcontractor and/or (b) terminate the Task Order and/or this Agreement for default.
Subcontractor shall maintain adequate insurance coverage and minimum coverage limits for its business as required by any applicable law or regulation, including Workers’ Compensation insurance as required by any applicable law or regulation, or otherwise as determined by Subcontractor in its reasonable discretion. Subcontractor’s lack of insurance coverage shall limit any liability Subcontractor may have under this Agreement or any Task Order issued hereunder.
1. Assignment. Subcontractor shall not assign any rights of this Agreement or any Task Order issued herein, and no assignment shall be binding without the prior written consent of Prime. Subject to the foregoing, this Agreement will be binding upon the Parties’ heirs, executors, successors and assigns.
2. Governing Law. The Parties shall make a good-faith effort to amicably settle by mutual agreement any dispute that may arise between them under this Agreement. The foregoing requirement will not preclude either Party from seeking injunctive relief as it deems necessary to protect its own interests. This Agreement will be construed and enforced in accordance with the laws of the Province of province, Canada, including its recognition of applicable federal law, but excluding such jurisdiction’s choice of law rules. The Parties consent to the exclusive jurisdiction and venue in province, Canada for the enforcement of any arbitration award or other judicial proceeding concerning this Agreement. Any judgment issued by such court shall award the prevailing Party its reasonable attorney’s fees and related costs. Both Parties agree that the occurrence of a dispute shall not interfere with either Party’s performance or other obligations under this Agreement.
3. Notice. All notices required under this Agreement will be in writing and will be sent to the address of the recipient specified above. Any such notice may be delivered by hand, by overnight courier or by first class pre‐paid letter, and will be deemed to have been received: (1) if delivered by hand ‐ at the time of delivery, (2) if delivered by overnight courier ‐ 24 hours after the date of delivery to courier with evidence of delivery from the courier, (3) if delivered by first class mail – three (3) business days after the date of mailing.
4. Injunctive Relief. Subcontractor acknowledges it would be difficult to fully compensate Prime for damages resulting from any breach by Subcontractor of the provisions of the following Sections of this Agreement: Exclusivity, Intellectual Property Rights, Confidentiality, Subcontracting, and Warranties. Accordingly, in the event of any actual or threatened breach of such provisions, Prime will, in addition to any other remedies that it may have, be entitled to temporary and/or permanent injunctive relief to enforce such provisions.
5. Severability. The Parties recognize the uncertainty of the law with respect to certain provisions of this Agreement and expressly stipulate that this Agreement will be construed in a manner that renders its provisions valid and enforceable to the maximum extent possible under applicable law. To the extent that any provisions of this Agreement are determined by a court of competent jurisdiction to be invalid or unenforceable, such provisions will be deleted from this Agreement or modified so as
to make them enforceable and the validity and enforceability of the remainder of such provisions and of this Agreement will be unaffected.
6. Independent Contractor. Nothing contained in this Agreement shall create an employer and employee relationship, a master and servant relationship, or a principal and agent relationship between Subcontractor and/or any Subcontractor employee(s) and Prime. Prime and Subcontractor agree that Subcontractor is, and at all times during this Agreement shall remain, an independent Subcontractor. The Subcontractor shall at all times be responsible for all Subcontractor’s employees’, agents, and subcontractor’s actions, shall be responsible for any applicable taxes or insurance, and shall comply with any applicable public laws or regulations.
7. Force Majeure. Neither Party shall be liable for any failure to perform under this Agreement when such failure is due to causes beyond that Party’s reasonable control, including, but not limited to, acts of state or governmental authorities, acts of terrorism, natural catastrophe, fire, storm, flood, earthquakes, accident, and prolonged shortage of energy. In the event of such delay the date of delivery or time for completion will be extended by a period of time reasonably necessary by both Subcontractor and Prime. If the delay remains in effect for a period in excess of thirty days, Prime may terminate this Agreement immediately upon written notice to Subcontractor.
8. Entire Agreement. This document and all attached or incorporated documents contains the entire agreement between the Parties and supersedes any previous understanding, commitments or agreements, oral or written. Further, this Subcontractor Agreement may not be modified, changed, or otherwise altered in any respect except by a written agreement signed by both Parties. IN WITNESS WHEREOF, this Subcontractor Agreement was signed by the Parties under the hands of their duly authorized officers and made effective as of the Effective Date.
[Sender.FirstName] [Sender.LastName] [Client.FirstName] [Client.LastName]